The following procedures apply to construction and building service contracts:

(a) The Government shall pay the final amount due the Contractor under this contract after the documentation in the payment clauses of the contract is submitted. This includes the final release prescribed for construction at FAR 52.232-5, and for building services at GSAR 552.232-72.

(b) Contracting officers may not process the final payment on construction or building service contracts until the contractor submits a properly executed GSA Form 1142, Release of Claims, except as provided in paragraph (c) of this section.

(c) In cases where, after 60 days from the initial attempt, the contracting officer is unable to obtain a release of claims from the contractor, the final payment may be processed with the approval of assigned legal counsel.

(d) The amount of final payment must include, as appropriate, deductions to cover any of the following:

(1) Liquidated damages for late completion.

(2) Liquidated damages for labor violations.

(3) Amount withheld for improper payment of labor wages.

(4) The amount of unilateral change orders covering defects and omissions.

[77 FR 6987, Feb. 10, 2012]


Tried the LawStack mobile app?

Join thousands and try LawStack mobile for FREE today.

  • Carry the law offline, wherever you go.
  • Download CFR, USC, rules, and state law to your mobile device.